Contract of Construction Project
合编号： Contract Number
工程名称： Project Name
发包方（甲方）： 工程设计顾问（北京）
Employer (Party A) International Consulting Engineers ( Beijing) Limited
承包方（乙方）： 中寰艺高建筑装饰工程限公司
Contractor (Party B) Zhong Huanyigao Building Decoration Engineering Co Ltd
根中华民国合法建筑安装工程承包合条例关规定明确双方施工程中权利义务济责双方协商意签订合
In order to make definite of the rights obligations and economic responsibilities of both parties during the construction the parties in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions agree to sign this contract
第条 工程项目Article 1 Project item
1． 工程点： Project site
2 工程范围： Scope of project
3 工程造价：民币 元整 (该造价包工包料价)
Project cost PMB Yuan only(Cost of this contract is the contract price for labor and materials)
第二条施工准备 Article 2 Preparation for construction
1． 甲方协助乙方办理时水电垂直运输提供建筑图纸关隐蔽障碍物资料
Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles
2． 乙方： Party B
① 负责施工区域时设施水电线铺设理维修工作
Be responsible for the works of laying management use and maintenance of the temporary facilities water and electricity pipeline in the construction area
② 组织施工理员材料施工机械进场
Organize construction management staff and construction materials construction machinery enter the Site
③ 负责装修期间保持公方清洁天负责装物料弃置理处指定垃圾收集处
Be responsible for keeping public places clean during construction and packing construction material and leaving in the garbage collection place designated by management office each day
第三条工程期限 Article 3 Period of Construction
1 根工期需商定工程总施工期 天（日历天） 年 月 日开工 年 月 日完工
According to the period of construction and the use need the total construction period agreed shall be days (Calendar days) start from the date of and complete on the date of
2． 遇列情况甲方现场代表签证工期相应延：
Construction period shall be prolonged upon Party A site representative＇s confirmation when the matters occur as follows
① 施工准备规定甲方未协助乙方办理时水电垂直运输影响进场施工
According to the requirements of construction preparation Party A fail tot assist Party B to apply for temporary water and electricity and vertical transportation and have an impact on Party B construction
② 甲方提出增减项目造成重设计变更影响进度
The material modification or change of design due to the party A’ s requirement of addition or deletion of project have the effect of hindrance on the progress of works
③ 未合规定拨付预付款工程款影响施工
Party A fail to pay the advance payment and construction cost to party B and impact the construction progress
④力抗拒素延误工期
The delay of schedule of construction due to Force Majeure
第四条 工程质量Article 4 The quality of project
． 工程质量双方研究求达双方约定验收标准
The quality of project should achieve the requirements of acceptance agreed by both parties
二． 乙方必须严格施工图纸说明文件国家颁发建筑工程规范规程标准进行施工接受甲方监督
Party B should carry on the construction in strict accordance with drawing specification file and regulations and specifications authorized by the competent authorities and be under the supervision of Party A
三． 乙方施工程中必须遵守列规定： Party B should during the construction comply with the provisions as follows
1． 乙方提供甲方材料必须甲方意方未求购买严禁
All materials provided by Party B should be subject to the approval of Party A prior to use And none of the same being bought without conformity with Party A requirements can be used
2． 隐蔽工程必须甲乙双方检查方进行道工序
The concealed works should be checked by both parties before the next progress
3． 工程竣工乙方规定工程实行保修保修时间通竣工验收日算起保修期年
Party B shall take the liability of maintenance following the complete of works The period of maintenance shall be one year from the day of acceptance of complete
第五条 工程价款支付结算Article 5 Payment and settlement of the contract price
合总价× 50 元 The total contract price × 50 which is Yuan
中期款The payment of mediumterm
工程进度半三日 Within 3 (three) days after the progress more than half
合总价× 40 元 The total contract price × 40 which is Yuan
尾款Final Payment
竣工验收结算七日Within 7 (seven) days after the completion acceptance and settlement
合总价× 10 元The total contract price × 10 which is Yuan
第六条 施工设计变更Article6 The Modification of Construction and Design
． 乙方交付设计图纸说明关技术资料作施工效开工前甲方组织签字认作施工补充甲乙双方均擅修改
Design drawing illustration and relevant technical data consigned by party B are the basis for construction and shall be confirmed by party A’s signature which is deemed as the supplementary basis and shall be modified by any party without authorization
二． 施工中发现甲方求发生设计错误严重合理方乙方应时书面形式通知甲方甲方时会乙方等关单位研究确定修改意见变更设计文件乙方修改变更设计文件进行施工发生增加费（包括返工损失停工窝工员机构设备调迁材料构配件积压实际损失）甲方负责调整合造价
If and when any error or material unreasonable problem of design due to party A’s requirement Party B shall notify Party A promptly in writing and decide the amendment or modification of the design documentation by the consultation and negotiation between parties and units concerned Party B shall carry out construction according to the design documents modified or changed If project cost increase (including the actual loss of rework loss stoppage or slowdown personnel and machine equipment relocated material structures fixtures backlog) shall be responsibility by Party A and be adjusted the contract price together with Party B
三． 乙方保证工程质量降低设计标准前提提出修改设计修改工艺合理化建议甲方设计单位关技术部门意采取实施
Any reasonable suggestion on the modifications of design and craft proposed by Party B subject to the quality and without reducing standards of design could be carried out upon the approval of Party A design unit or concerned technical department
四． 甲方需设计变更必须作出正式修改通知书修改图纸乙方予实施重修改增加造价时必须行协商乙方予实施
Party A should if any necessary design change make the formal amendment and modify drawings for Party B’s implementation Material changes and cost increased must be negotiated by both parties before Party B implement the same
第七条 工程验收Article 7 Acceptance of project
． 工程施工中工程结构工程必须具隐蔽验收签证试水抗渗等验收合格记录甲方须时办理验收签订手续
The underground engineering structural engineering in the construction of project should be checked and with issue of certificate and the record of acceptance of water test antipermeability and so on Party A should deal with the acceptance signed formalities timely
二． 工程竣工验收甲方Party A can use the project after completion acceptance
规定保修期施工造成质量缺陷应乙方偿保修保修条件范围期限城乡建设环境保护部（84）城建字第79号通知印发建筑工程保修办法（试行）执行
In the provision warranty period any construction quality defects Party B should make maintenance free of the quality defect due to construction the scope and duration carry out according to the issuance of Cheng Jian No 79 notification Construction engineering guarantee measures (Trial) by Urban and Rural Construction and Environmental Protection Department (84)
第八条 违约责Article 8 Liability for breach of contract
乙方责：Responsibility of Party B
． 工程质量符合合规定负责偿修理返工
Take charge of gratis repair and rework if project quality doesn＇t meet contact＇s stipulation
二． 工程合规定工期交付合中关建设工期提交拖奖罚规定偿付逾期罚款
If fail to deliver the construction according to the contract on time The overdue fines according to punishment or award of the provision concerning the delivery or delay
甲方责：The responsibility of Party A
． 未合规定履行应负责竣工日期延外应赔偿乙方造成实际损失
Failed to fulfill their responsibilities in accordance with the provisions of the contract in addition to the completion date to be postponed should be compensation for the actual loss of Party B
二． 工程中途停建缓建设计变更设计错误造成返工应采取措施弥补减少损失时赔偿乙方造成停工窝工返工倒运员机械设备调迁材料构件积压实际损失
The ongoing project is stopped postponed or due to design changes and rework caused by design errors should take measures to remedy or reduce losses At the same time compensate Party B the actual loss of work stoppage slowdown redispatch rework reshipment staff and mechanical equipment relocating the backlog of materials and components
第九条 纠纷解决办法Article 9 Dispute settlement
方违反合规定双方协商成均北京仲裁委员会申请仲裁
Either party could if any party’s breach and fail to negotiation submit the application of arbitration to the Beijing Arbitration Committee
第十条 附Article 10 Supplementary
．合式贰份甲乙双方执正份
This contract is execute in two counterparts each party holds a single original
二． 合双方代表签字加盖双方公章合专章生效工程竣工验收符合求保修期满合终止
The contract becomes effective after signing and sealing by both parties on this foregoing date The project final acceptance meet the requirements after the expiry of warranty ends the contract
甲方（盖章）：Party A (seal) 乙方（盖章）： Party B (seal)
委托代理（签章）：Agent 委托代理（签章）：Agent
电话：Tel 电话：Tel
日期：Date 日期：Date
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档
合编号： Contract Number
工程名称： Project Name
发包方（甲方）： 工程设计顾问（北京）
Employer (Party A) International Consulting Engineers ( Beijing) Limited
承包方（乙方）： 中寰艺高建筑装饰工程限公司
Contractor (Party B) Zhong Huanyigao Building Decoration Engineering Co Ltd
根中华民国合法建筑安装工程承包合条例关规定明确双方施工程中权利义务济责双方协商意签订合
In order to make definite of the rights obligations and economic responsibilities of both parties during the construction the parties in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions agree to sign this contract
第条 工程项目Article 1 Project item
1． 工程点： Project site
2 工程范围： Scope of project
3 工程造价：民币 元整 (该造价包工包料价)
Project cost PMB Yuan only(Cost of this contract is the contract price for labor and materials)
第二条施工准备 Article 2 Preparation for construction
1． 甲方协助乙方办理时水电垂直运输提供建筑图纸关隐蔽障碍物资料
Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles
2． 乙方： Party B
① 负责施工区域时设施水电线铺设理维修工作
Be responsible for the works of laying management use and maintenance of the temporary facilities water and electricity pipeline in the construction area
② 组织施工理员材料施工机械进场
Organize construction management staff and construction materials construction machinery enter the Site
③ 负责装修期间保持公方清洁天负责装物料弃置理处指定垃圾收集处
Be responsible for keeping public places clean during construction and packing construction material and leaving in the garbage collection place designated by management office each day
第三条工程期限 Article 3 Period of Construction
1 根工期需商定工程总施工期 天（日历天） 年 月 日开工 年 月 日完工
According to the period of construction and the use need the total construction period agreed shall be days (Calendar days) start from the date of and complete on the date of
2． 遇列情况甲方现场代表签证工期相应延：
Construction period shall be prolonged upon Party A site representative＇s confirmation when the matters occur as follows
① 施工准备规定甲方未协助乙方办理时水电垂直运输影响进场施工
According to the requirements of construction preparation Party A fail tot assist Party B to apply for temporary water and electricity and vertical transportation and have an impact on Party B construction
② 甲方提出增减项目造成重设计变更影响进度
The material modification or change of design due to the party A’ s requirement of addition or deletion of project have the effect of hindrance on the progress of works
③ 未合规定拨付预付款工程款影响施工
Party A fail to pay the advance payment and construction cost to party B and impact the construction progress
④力抗拒素延误工期
The delay of schedule of construction due to Force Majeure
第四条 工程质量Article 4 The quality of project
． 工程质量双方研究求达双方约定验收标准
The quality of project should achieve the requirements of acceptance agreed by both parties
二． 乙方必须严格施工图纸说明文件国家颁发建筑工程规范规程标准进行施工接受甲方监督
Party B should carry on the construction in strict accordance with drawing specification file and regulations and specifications authorized by the competent authorities and be under the supervision of Party A
三． 乙方施工程中必须遵守列规定： Party B should during the construction comply with the provisions as follows
1． 乙方提供甲方材料必须甲方意方未求购买严禁
All materials provided by Party B should be subject to the approval of Party A prior to use And none of the same being bought without conformity with Party A requirements can be used
2． 隐蔽工程必须甲乙双方检查方进行道工序
The concealed works should be checked by both parties before the next progress
3． 工程竣工乙方规定工程实行保修保修时间通竣工验收日算起保修期年
Party B shall take the liability of maintenance following the complete of works The period of maintenance shall be one year from the day of acceptance of complete
第五条 工程价款支付结算Article 5 Payment and settlement of the contract price
合总价× 50 元 The total contract price × 50 which is Yuan
中期款The payment of mediumterm
工程进度半三日 Within 3 (three) days after the progress more than half
合总价× 40 元 The total contract price × 40 which is Yuan
尾款Final Payment
竣工验收结算七日Within 7 (seven) days after the completion acceptance and settlement
合总价× 10 元The total contract price × 10 which is Yuan
第六条 施工设计变更Article6 The Modification of Construction and Design
． 乙方交付设计图纸说明关技术资料作施工效开工前甲方组织签字认作施工补充甲乙双方均擅修改
Design drawing illustration and relevant technical data consigned by party B are the basis for construction and shall be confirmed by party A’s signature which is deemed as the supplementary basis and shall be modified by any party without authorization
二． 施工中发现甲方求发生设计错误严重合理方乙方应时书面形式通知甲方甲方时会乙方等关单位研究确定修改意见变更设计文件乙方修改变更设计文件进行施工发生增加费（包括返工损失停工窝工员机构设备调迁材料构配件积压实际损失）甲方负责调整合造价
If and when any error or material unreasonable problem of design due to party A’s requirement Party B shall notify Party A promptly in writing and decide the amendment or modification of the design documentation by the consultation and negotiation between parties and units concerned Party B shall carry out construction according to the design documents modified or changed If project cost increase (including the actual loss of rework loss stoppage or slowdown personnel and machine equipment relocated material structures fixtures backlog) shall be responsibility by Party A and be adjusted the contract price together with Party B
三． 乙方保证工程质量降低设计标准前提提出修改设计修改工艺合理化建议甲方设计单位关技术部门意采取实施
Any reasonable suggestion on the modifications of design and craft proposed by Party B subject to the quality and without reducing standards of design could be carried out upon the approval of Party A design unit or concerned technical department
四． 甲方需设计变更必须作出正式修改通知书修改图纸乙方予实施重修改增加造价时必须行协商乙方予实施
Party A should if any necessary design change make the formal amendment and modify drawings for Party B’s implementation Material changes and cost increased must be negotiated by both parties before Party B implement the same
第七条 工程验收Article 7 Acceptance of project
． 工程施工中工程结构工程必须具隐蔽验收签证试水抗渗等验收合格记录甲方须时办理验收签订手续
The underground engineering structural engineering in the construction of project should be checked and with issue of certificate and the record of acceptance of water test antipermeability and so on Party A should deal with the acceptance signed formalities timely
二． 工程竣工验收甲方Party A can use the project after completion acceptance
规定保修期施工造成质量缺陷应乙方偿保修保修条件范围期限城乡建设环境保护部（84）城建字第79号通知印发建筑工程保修办法（试行）执行
In the provision warranty period any construction quality defects Party B should make maintenance free of the quality defect due to construction the scope and duration carry out according to the issuance of Cheng Jian No 79 notification Construction engineering guarantee measures (Trial) by Urban and Rural Construction and Environmental Protection Department (84)
第八条 违约责Article 8 Liability for breach of contract
乙方责：Responsibility of Party B
． 工程质量符合合规定负责偿修理返工
Take charge of gratis repair and rework if project quality doesn＇t meet contact＇s stipulation
二． 工程合规定工期交付合中关建设工期提交拖奖罚规定偿付逾期罚款
If fail to deliver the construction according to the contract on time The overdue fines according to punishment or award of the provision concerning the delivery or delay
甲方责：The responsibility of Party A
． 未合规定履行应负责竣工日期延外应赔偿乙方造成实际损失
Failed to fulfill their responsibilities in accordance with the provisions of the contract in addition to the completion date to be postponed should be compensation for the actual loss of Party B
二． 工程中途停建缓建设计变更设计错误造成返工应采取措施弥补减少损失时赔偿乙方造成停工窝工返工倒运员机械设备调迁材料构件积压实际损失
The ongoing project is stopped postponed or due to design changes and rework caused by design errors should take measures to remedy or reduce losses At the same time compensate Party B the actual loss of work stoppage slowdown redispatch rework reshipment staff and mechanical equipment relocating the backlog of materials and components
第九条 纠纷解决办法Article 9 Dispute settlement
方违反合规定双方协商成均北京仲裁委员会申请仲裁
Either party could if any party’s breach and fail to negotiation submit the application of arbitration to the Beijing Arbitration Committee
第十条 附Article 10 Supplementary
．合式贰份甲乙双方执正份
This contract is execute in two counterparts each party holds a single original
二． 合双方代表签字加盖双方公章合专章生效工程竣工验收符合求保修期满合终止
The contract becomes effective after signing and sealing by both parties on this foregoing date The project final acceptance meet the requirements after the expiry of warranty ends the contract
甲方（盖章）：Party A (seal) 乙方（盖章）： Party B (seal)
委托代理（签章）：Agent 委托代理（签章）：Agent
电话：Tel 电话：Tel
日期：Date 日期：Date
文档香网(httpswwwxiangdangnet)户传
《香当网》用户分享的内容，不代表《香当网》观点或立场，请自行判断内容的真实性和可靠性！
该内容是文档的文本内容，更好的格式请下载文档
